Terms and Conditions
Effective Date
Terms and Conditions
Welcome to Christie Building & Development, Inc. By engaging our services, visiting our website, requesting a proposal, or entering into a construction agreement with us, you agree to the following Terms and Conditions. Please review them carefully.
Christie Building & Development, Inc. is a licensed California General Contractor. License information is available through the California Contractors State License Board (CSLB).
1. Services Provided
Christie Building & Development provides general contracting, construction management, tenant improvement, renovation, remodeling, and related construction services throughout Southern California.
The scope of work, project schedule, pricing, specifications, and deliverables will be defined in a written proposal, contract, or change order executed by both parties.
2. Client Responsibilities
To help ensure successful project delivery, clients agree to:
Provide accurate and complete project information.
Respond promptly to requests for approvals, selections, and project decisions.
Provide timely access to the project site when required.
Secure financing necessary for project completion.
Obtain approvals from property owners, landlords, homeowners associations, or other governing entities when applicable.
Review and approve project documents, schedules, and change orders in a timely manner.
Delays in client decisions or approvals may impact project schedules and costs.
3. Pricing and Payment
Project pricing will be outlined in the applicable proposal or contract.
Payments are due according to the schedule established in the agreement.
Late payments may be subject to interest charges as permitted by California law.
Work may be suspended if payments are not received as agreed.
Change orders requested by the client may result in additional costs and schedule adjustments.
Deposits and payments for completed work are non-refundable unless otherwise stated in writing.
4. Permits and Regulatory Compliance
Christie Building & Development will obtain permits when specifically included within the project scope.
Permit approval timelines are controlled by local agencies and may affect project schedules. We are not responsible for delays caused by permitting authorities, inspections, utility providers, or other governmental agencies.
Clients remain responsible for any approvals not specifically included in the contract.
5. Project Schedule
Construction schedules are estimates and may be affected by:
Weather conditions
Material availability
Labor shortages
Permit processing
Inspection scheduling
Utility coordination
Unforeseen site conditions
Client-requested changes
While we strive to maintain project schedules, completion dates cannot be guaranteed unless expressly stated in writing.
6. Change Orders
Any work requested outside the original scope of the agreement must be documented through a written Change Order.
Change Orders may affect:
Project cost
Schedule
Materials
Labor requirements
Work outside the original scope will not proceed until approved by both parties.
7. Site Conditions
Construction projects may reveal concealed or unforeseen conditions, including but not limited to:
Structural deficiencies
Hazardous materials
Utility conflicts
Water intrusion
Code compliance issues
Any necessary corrective work resulting from such discoveries will be treated as additional work and may require a Change Order.
8. Warranty
Christie Building & Development warrants workmanship in accordance with the terms outlined in the project contract and applicable California law.
This warranty does not cover:
Normal wear and tear
Improper use or maintenance
Damage caused by third parties
Acts of nature
Manufacturer defects covered by separate manufacturer warranties
Warranty claims must be submitted in writing within the applicable warranty period.
9. Limitation of Liability
To the fullest extent permitted by law, Christie Building & Development shall not be liable for indirect, incidental, consequential, special, or punitive damages arising from any project, agreement, or use of our services.
Our total liability shall not exceed the amount paid to Christie Building & Development under the applicable contract.
10. Confidentiality
Both parties agree to maintain the confidentiality of proprietary, financial, and project-related information obtained during the course of the project.
Unless otherwise requested in writing, Christie Building & Development may photograph and showcase completed projects for marketing, portfolio, and promotional purposes.
11. Termination
Either party may terminate the agreement according to the terms outlined in the applicable contract.
Upon termination, the client shall be responsible for payment of:
Completed work
Materials ordered
Costs incurred
Approved Change Orders
Demobilization expenses, if applicable
12. Dispute Resolution
The parties agree to make reasonable efforts to resolve disputes through good-faith discussions.
If a dispute cannot be resolved informally, the parties agree to pursue mediation before initiating litigation, unless otherwise required by law.
13. Governing Law
These Terms and Conditions shall be governed by the laws of the State of California.
Any legal proceedings shall be brought in a court of competent jurisdiction located within the State of California.
14. Website Use
Information provided on this website is for general informational purposes only and does not constitute a binding proposal, estimate, or contractual commitment.
Project pricing, timelines, and scope are subject to review and approval through a formal written agreement.
15. Changes to These Terms
Christie Building & Development reserves the right to update or modify these Terms and Conditions at any time.
Updated versions will be posted on this website with a revised effective date.
15. Contact Us
If you have questions about these terms, please contact us:
Christie Building & Development
1000 Business Center Circle Suite 102
Newbury Park, CA 91320
Phone: (818) 292-9571
Email: info@christiebuilding.com